This Software Development Agreement states the terms and conditions that govern the contractual agreement between the company (Neo MLM Softwares) having his principal place of business at poozikunnu,INDIA , and Customer(Company)
Terms and Conditions between Neo MLM Softwares and Clients covenant and agree as follows:
The Client hereby engages the Developer and the Developer hereby agrees to be engaged by the Client to develop the Software in accordance with the specifications attached hereto as Exhibit A (the “Specifications”).
1. The Developer shall complete the development of the Software according to the milestones described on the form attached hereto as Exhibit B. In accordance with such milestones, the final product shall be delivered to the Client by [FINAL DELIVERY DATE] (the “Delivery Date”).
2. For a period of [TIME FRAME] after delivery of the final product, the Developer shall provide the Client attention to answer any questions or assist solving any problems with regard to the operation of the Software up to [NUMBER] of hours free of charge and billed to the Client at a rate of [RATE] per hour for any assistance thereafter. The Developer agrees to respond to any reasonable request for assistance made by the Client regarding the Software within [RESPONSE TIME] of the request.
3. Except as expressly provided in this Software Development Agreement, the Client shall not be obligated under this Agreement to provide any other support or assistance to the Developer.
4. The Client may terminate this Software Development Agreement at any time upon material breach of the terms herein and failure to cure such a breach within [TIME TO CURE BREACH] of notification of such a breach.
5. The Developer shall provide to the Client after the Delivery Date, a cumulative [TIME OF TRAINING] of training with respect to the operation of the Software if requested by the Client.
The Software shall function in accordance with the Specifications on or before the Delivery Date.
1. If the Software as delivered does not conform with the Specifications, the Client shall within [DAYS TO NOTIFY] of the Delivery Date notify the Developer in writing of the ways in which it does not conform with the Specifications. The Developer agrees that upon receiving such notice, it shall make reasonable efforts to correct any non-conformity.
2. The Client shall provide to the Developer written notice of its finding that the Software conforms to the Specifications within [NUMBER DAYS OF DELIVERY] days of the Delivery Date (the “Acceptance Date”) unless it finds that the Software does not conform to the Specifications as described in Section 2(A) herein.
In consideration for the Service, the Client shall pay the Company at the rate of [RATE] , with a maximum total fee for all work under this Software Development Agreement of [MAXIMUM TOTAL FEE]. Invoices will be provided for work completed by the company once every [PAY PERIOD].
The Parties acknowledge and agree that the Client will hold all intellectual property rights in the Software including, but not limited to, copyright and trademark rights. The Developer agrees not to claim any such ownership in the Software’s intellectual property at any time prior to or after the completion and delivery of the Software to the Client.
The Client may request that reasonable changes be made to the Specifications and tasks associated with the implementation of the Specifications. If the Client requests such a change, the Developer will use its best efforts to implement the requested change at no additional expense to the Client and without delaying delivery of the Software. In the event that the proposed change will, in the sole discretion of the Developer, require a delay in the delivery of the Software or would result in additional expense to the Client, then the Client and the Developer shall confer and the Client may either withdraw the proposed change or require the Developer to deliver the Software with the proposed change and subject to the delay and/or additional expense. The Client agrees and acknowledges that the judgment as to if there will be any delay or additional expense shall be made solely by the Developer.
The Developer shall no longer disclose to any third party the business of the customer, information regarding the software, including, without limitation any information regarding the Software’s code, the Specifications, or the Client’s business (the “Confidential Information”), (ii) make copies of any Confidential Information or any content based on the concepts contained within the Confidential Information for personal use or for distribution unless requested to do so by the Client, or (iii) use Confidential Information other than solely for the benefit of the Client.
The Developer represents and warrants to the customer the following:
1. Development and delivery of the Software below this agreement are not in violation of another agreement that the Developer has with every other party.
2. The Software will not violate the intellectual property rights of any other party.
3. For a length of [TIME FRAME AFTER DELIVERY DATE] after the Delivery Date, the software program shall perform in step with the specs. If the Software malfunctions or in any way does no longer perform consistent with the specifications inside that time, then the Developer shall take any reasonably necessary steps to fix the issue and ensure the Software operates according to the Specifications.
The Developer agrees to indemnify, protect, and shield the customer from and in opposition to all lawsuits and expenses of every type bearing on the software including reasonable prison charges due to the Developer’s infringement of the intellectual rights of any third party.
No change of this settlement shall be legitimate unless in writing and agreed upon by way of each parties.